PATTON DRIVE CIGP PROJECT #50141172 NOTICE TO RECEIVE SEALED BIDS The Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: PATTON DRIVE CIGP FPID NO. 449878-1-54-01 The project is the widening and resurfacing of Patton Drive for approximately 0.74 miles from Island Drive (SR 300) to U.S. Highway 98. Other work to include necessary drainage improvements, upgraded signage and pavement markings and safety improvements. Plans and specifications can be obtained by contacting Shannon Renfro with Dewberry at srenfro@dewberry.com. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. All bidders shall be FDOT qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Constructions, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant mix-Bituminous Course. Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day. Please indicate on the envelope that this is a sealed bid, for “PATTON DRIVE CIGP”. Bids will be received until 4:30 p.m. eastern time, on November 18th, 2025 , at the Franklin County Clerk's Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-2317, and will be opened and read aloud on Wednesday, November 19th, 2025 , at the County Commission meeting at 34 Forbes Street, Apalachicola, FL. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. All technical questions must be addressed in writing and emailed to Josh Stephens at jstephens@dewberry.com no later than November 4th, 2025. Pub: 10/8/25 10/15/25 #11728526